Amounts which accrue to the Owner in accordance with this provision shall be credited to the Owner as a 17. Engineering construction workers operating under the Blue Book agreement have accepted contractors' offer of a extra 1 a hour cost of living increase. In the event the Owner takes over the Work pursuant to this completed in accordance with this Agreement, except for punch list items; (ii)the Owner has received any required temporary or final certificate of occupancy from the governmental agency with jurisdiction over the Project; and (iii)the Outlays on private non-residential structures like gas and oil well drilling increased 0.9% in January. Audit. avoidable interference in or delays to the Work caused by the Owners own forces or separate contractors. The Owners election to take over all or any part of the Work shall not constitute the Owners sole remedy upon any such default. time shall state the number of days claimed and the reason for the delay. Can a new employer ask for my last pay stub? warranty. The Articles of Agreement . The Owner may cancel this Agreement at any time and for any reason, without cause and for its convenience, upon written notice to the Contractor. If within a reasonable time after the occurrence of an event of Force Majeure Event that has caused Contractor to suspend or Below is a list of common sections included in Construction Agreements. completed except as agreed in writing in advance by the Contractor. Securely pay to start working with the lawyer you select. Post a projectin ContractsCounsel's marketplace to get free bids from lawyers to draft, review, or negotiate construction agreements. The articles contain details regarding items such as voting rights, company limitations, and other entity powers. c. The Commercial General Liability insurance shall be primary and non-contributory with the In visiting the Project site and the Work, the Owner and its representatives shall not unreasonably interfere with or delay the performance of the Work, whether performed by the Contractor or the Work performed up to the effective date of the termination (Contractors Fee at termination = (Contractors Fee) x (Cost of the Work performed up to the effective date of termination / Sum of Payments in Exhibit B, as amended)), of the Work at the site or in Contractors fabrication facilities. And see Id. The Contractor is an independent contractor and employing unit and shall be responsible for taxes or contributions payable on its employees, including without limitation employee contributions under The Contractors subcontracts and supply contracts shall require the Subcontractor, to the extent of the Work to be performed by In Contractor shall be responsible for all the acts and omissions of Subcontractors and their employees and agents. Should any suit, action or arbitration be commenced in connection with any dispute arising out of this Agreement, to obtain a judicial conditions. Times for any extra or additional work or for work outside the scope of the Agreement, except as set out in this Section10. Only to the extent necessary to fulfill. I'm now working in-house and have a wide range of experience with commercial and corporate contracts as well as legal and regulatory research. Banks often require the use of AIA contracts and forms on projects they are financing. 22. The articles of agreement is a legal document that sets the foundation for a business entity regarding certain operational aspects of it. Because there are so many different types of construction projects, each type of construction contract exists to satisfy the varying needs of all parties involved. (as further described below, the Cost of the Work), which shall exclude any components supplied by Owner or others. I have extensive experience in providing legal services and support in areas of business, labor & employment, IP enforcement (patent infringement, copyright & trademark), and other litigation matters; Reviewing, drafting, and editing business and legal documents/contracts; Conducting legal research and analysis, drafting memorandums, pleadings, discovery, document review, various motions, mediation briefs, and other litigation related activities; Reviewing and preparation of templates, policies, and processes for compliance with laws and regulations; educating and advising on legal and compliance issues. Notwithstanding any provision of this Agreement and to the extent permitted by law, neither the Owner nor the Contractor, nor any of each of their subsidiaries, affiliates, directors, officers, employees or agents, be liable to the other party for State of Texas - questions regarding an online business (Nanny Placement Agency) in the Houston area. If the Contractor continues to perform, the Owner shall continue to make payments in accordance with this Agreement. been achieved and will continue for the lesser of (i)twelve (12)months from the applicable Guaranteed Mechanical Completion Date; or 18 months after the applicable Final Completion Date (Base Warranty Period). notice within which the Contractor recommences the Work) plus an equitable increase in the Contractors Fee. presented in accordance with all requirements of this paragraph shall be deemed waived and forever discharged. The decision of the arbitrators shall be final and judgment upon the award may be entered into any court having jurisdiction thereof. other form of memory or recording, describing and necessary for the Work to be performed (the Plans). In the event that change orders and/or added or deleted Work increase or decrease the The Contractor confirms that the Owner and its successors and assigns shall own the Contractors right, title and interest in 38.2 Suspension of Performance. No matter the client, I always look for ways to protect their assets, artworks, businesses, and brands with strategies to help them grow. claims brought by employees or agents under the Industrial Insurance provisions of RCW Title 51. The Owner shall be responsible for any Majeure Event. be modified only by a subsequent writing signed by both parties. 40.2 Arbitration. 5.8 Costs of installing equipment and components furnished by the Owner (Owner-Furnished Components). All drawings, specifications, calculations, certifications and submittals prepared by such design professionals shall bear the signature in the Contractors Fee, and any agreed changes in the Contract Times. 34.1.3 Comprehensive Automobile Liability, applicable to any automobile, including owned, non-owned, and hired automobiles, with limits of liability of not less than $1,000,000 combined single limit for Bodily Injury and Property Damage Form of Works contract is executed amongst the following persons. All work described and incorporated on any Exhibit A hereto shall be collectively referred to as the Work. jurisdiction where the Project is located; provided, however, that nothing in this Section30.1 shall be construed to limit the Contractors obligations under Section16.2. Agreement shall be conclusively considered to contain and express all the terms and conditions agreed upon by the parties, notwithstanding any prior or contemporaneous written communication, promise, understanding or agreement. observation and approval by the Owner and representatives of governmental agencies with jurisdiction over the Project. Non-disclosure agreements (NDAs) are amongst the most common agreements that come across an in-house attorney's desk. of work described on Exhibit A, a form of which is attached hereto, said Work (hereinafter defined) to performed as part of Owners biodiesel production facility located at Grays Harbor, Washington (the Project). Certificates of such insurance shall be filed with the Owner prior to the commencement of the Work. 9.4 The Contractor shall achieve Final Completion (as hereinafter Final payment shall be made upon Mechanical Completion of the Work, subject to the provisions of Section8.2. without limitation those governing labor, materials, equipment, construction procedures, safety, health, sanitation and the environment. damages, expenses, penalties, actions, suits or liabilities are caused by the negligence, breach of contract, breach of warranty, or other wrongful acts or omissions, whether active or passive, including but not limited to failure to comply with for personally managing and administering the performance of the Contractors obligations under this Agreement, subject to his continuing employment by Contractor and the needs, staffing and skill requirements of the specific Project stage). nonconforming Work, (3)claims filed or a reasonable basis to believe that such claims will be filed imminently, (4)failure of the Contractor to make payments properly for labor, services, materials, equipment or subcontracts, (5) damages Project site and to the Work wherever being performed. Thanks for submitting. names to appear on the insurance policies. the Contractor, in a bank account in the name of the Contractor or its affiliate. action arising out of or related to this Agreement shall be commenced and conducted in Olympia, Washington. The Contractor If any proceeding is instituted against the Contractor Claims for Damages. The Agreement contains the general terms and conditions which will govern all future specifications and scope intended to be issued to and performed by Contractor with respect to the Payment. possession of the site and all of the Contractors materials, equipment, tools, construction equipment and machinery and complete all or any part of the 5.12 Costs relating to any general conditions and overhead reasonably allocable to the Work and not to any other project. Hi there. seeking to adjudicate the Contractor as bankrupt or insolvent and such proceeding is not dismissed within sixty (60)days of filing, or if the Contractor makes a general assignment for the benefit of its creditors, or if a receiver is appointed final payment, as set out in this Section8. in the performance of the Work if and to the extent approved in advance in writing by the Owner. Dispute Resolution. 40.1 Initial Dispute Resolution. Contractor shall submit any claim for an extension of time to the Owner, in writing, within ten (10)days after the commencement of the delay. The Owner shall be responsible for purchasing and maintaining the Owners usual liability insurance, I am fluent in Spanish and English. under any other contract without the specific approval of the Owner in writing in advance. In lieu of actual delay damages, the Owner and Contractor agree that if Mechanical Completion is not achieved by the applicable Guaranteed Mechanical Completion Date, the amount of the Owners actual damages will be difficult to determine. copyrightable and whether reduced to practice, (ii)all patents and patent rights, copyrights, trade secrets, trademarks, and other similar property rights, and (iii)all Project process or operational writings, records, journals, An article is a memorandum or minute of an agreement, reduced to writing to make some future disposition or modification of property; and such an instrument will create a trust or equitable estate, of which a specific performance will be decreed in chancery. expense. 23.1 Immediately upon discovery, the Contractor shall cease performance of the Work in that area of the Project where there are, or reasonably appear to be, the following: (a)materials which are or which it Such consolidated mediation and arbitration otherwise shall be governed by the terms of this Section40. Schedule of Values, attached as Exhibit B, provided solely as a preliminary estimate of cash flow needs for the Owner. A court agreement would drop the number of signatures needed to force a recall election. as well as a builders all-risk policy form naming the Contractor as an additional insured. construction lien foreclosure suit shall be stayed pending the arbitration. The The Contractor shall, when practicable, solicit competitive bids from qualified subcontractors before seeking the Owners approval for work of the magnitude described in the previous sentence. 2. A construction agreement is a legally binding document that outlines the terms and conditions of a construction project. Cleanup. These costs include items such as utilities, telecommunications, water coolers, portable toilets, etc. 5.4 Costs paid or incurred by the Contractor for employee-related Cruise on Real Pr. The effective date of any notice issued pursuant to this Agreement shall be the earlier of Agreement or as soon thereafter as reasonably possible, the Owner shall provide the Contractor with evidence of financing in a mutually agreeable form, which shall include a deposit of the Contract Price, including any bonus potentially payable to Authors. The Contractor shall not delegate its obligations to the Owner under this Agreement in whole or in part, nor shall any rights of derivative works from all Developments. thereon for the Work performed up to the date of termination, plus the Contractors demobilization and other costs directly relating to the termination, minus any cost incurred by the Owner to the extent caused by Contractor or those for whom shall cooperate fully in the audit. Owners Construction and Separate Contracts. The Contractor agrees that its indemnification obligations extend to claims, demands, and causes of action 10. federal or state laws and full compliance with record keeping, reporting and other requirements of such laws. If any liens arising out of the Work are filed by any person or entity, including without limitation any Subcontractor, the Contractor shall, at its cost and within ten (10)days after demand from the Contractor will agree to perform contracting services relating to biodiesel and glycerin exclusively for Owner so long as stopped or suspended by order of any court or governmental authority, within seven (7)days after receipt of notice that such Work stoppage or suspension is removed, the Contractor shall complete the Work as expeditiously as reasonably 9.1 The Contractor has already commenced performance of the Work pursuant to a Limited Notice to Proceed executed by the Owner and the Contractor on July14, 2006. The relationship between users and ContractsCounsel are not protected as attorney-client privilege or as legal work product. The Madison County Fiscal Court unanimously approved an interlocal agreement with the Richmond City Commission to create a men's rehabilitation center with the opioid settlement funds both . 25. When not helping clients, Jonathan enjoys reading, Republican politics, spending time with family, traveling, and working on his "Freedom Friday" blog. The Owners rights under this Section shall be subject to the rights of the Contractors surety and the Contractors If the Contractor fails to provide acceptable policies of insurance, the Owner may obtain such insurance at the cost and the expense of the Contractor. All remaining costs shall be at rates comparable to the standard paid at the place of the Project . No: Status of person: Name: . To the fullest extent permitted by law, the Contractor shall defend, hold harmless, reimburse and indemnify the Owner, and its architect and engineer, and their partners, owners, members, officers, agents and employees 8.2 The Owner may withhold all or a portion of a progress payment or final payment on account of (1)incomplete Work, (2)defective or Renco USA has the exclusive rights in the USA to the patented process. changes, which shall be subject to arbitration if demanded by the Contractor. If requested by Owner, the Contractor shall secure and initially pay for the building Title to all equipment and materials to be incorporated into the Project shall pass to Owner upon delivery of such equipment and materials to the Project site or when Contractor receives payment relating to the equipment and materials, whichever Work and such other damages as the Owner may sustain as a result of the Contractors default. Only to the extent necessary to fulfill those obligations, the Owner, by mutual negotiation, hereby waives any immunity that would otherwise be available against Limitation of Liability. The name of the Corporation, the objects for which it is established and . As used in this Agreement, the term Subcontractors shall include all subcontractors and suppliers under a direct contract with Contractor. thereunder, 36. Unless otherwise agreed in writing, the otherwise resolved by agreement of the Owner and the Contractor; and (vi)Liquidated Damages, if applicable, have paid to Owner. The Owner agrees that its indemnification obligations extend to claims, (i)the addressees receipt of such notice and (ii)the date three days after such notice was sent by properly addressed, registered or certified mail: IN WITNESS WHEREOF, the Owner and the Contractor have caused this Agreement to be executed in two Following a . Accordingly, the Owner and the Contractor agree that in the event the Contractor fails to achieve Mechanical Completion by the applicable Guaranteed Mechanical Completion Date, the Contractor shall pay to the Owner as liquidated damages to The Purpose of an NDA. be settled pursuant to Section40.2, the parties shall settle the dispute by binding arbitration under the current Construction Industry Arbitration Rules of the American Arbitration Association. The Contractor shall keep the Project and Project property free and clear of all Period). The rights and remedies under this Section37 shall not be deemed to limit Owners ability to seek any other rights and remedies provided by this If the Contractor is ready, able and willing to work but is delayed at any time during the progress of the Work by any act or neglect 22.2 Any work performed by Section, the Owner may dispose of excess materials and debris as it determines appropriate, in its sole discretion. Sample 1 Sample 2 Sample 3. 5.5 Actual payments made by the Contractor to Subcontractors in accordance with the requirements of the applicable subcontracts and supply contracts, and 12, c. 1. brought by or on behalf of its employees or agents. But parts of the agreement are vague - talks veterans refer to the "constructive ambiguity" required to forge a deal that one side could sell to its supporters as a step towards a united Ireland . Should the Contractor fail to perform its obligations under this Section, the Owner may do so at the Contractors provisions of Section33.1, the Contractor shall bear the risk of loss of and damage to, and shall be obligated to repair, replace, or reconstruct, or pay for. Contractor for the cost of the building permit (but there shall be no Contractor fee or markup thereon). 10. Each of the Contract Documents plays its own role in establishing the rights and duties of the contractor and the owner. I am a dual qualified (Illinois; England & Wales) transactional lawyer with about 5 years of experience. The five main types of construction contracts are lump sum, time and materials, cost-plus, unit price, and guaranteed maximum price (GMP). of warranty, or other wrongful acts or omissions, whether active or passive, including but not limited to failure to comply with applicable laws, on the part of the Owner, its contractors, or the partners, officers, directors, agents, or employees subsidiary company, or to a company growing out of a consolidation or acquisition by or of, or merger with, the assigning party. Because AIA documents are used on so many projects, their templates have become the "norm" in the industry. Such insurance shall be written on an occurrence basis and shall be maintained maintain one (1)record set of such documents; all other sets and copies of such documents shall be returned to the Owner upon Mechanical Completion of the Work. Work, including without limitation the Drawings and Specifications listed therein, attached as Exhibit A. 9.6 The Owner and Contractor agree that if Mechanical Completion for the Work occurs prior to the Guaranteed Mechanical Completion Date, the Owner shall No oral communication, promise, understanding, or agreement before, contemporaneous with or after the execution of this Agreement shall affect or modify any of its terms or obligations. We will be in touch shortly! 20. any of the Contractors payment obligations directly to the claimant or by multiple payee check to the Contractor and the claimant and parties in intervening tiers, if any, and deduct the amount of such payment from amounts due or to become due convenience, the Owner shall pay the Contractor the reasonable Cost of the Work plus the Contractors Fee, in an amount equal to the Cost of the Work performed up to the effective date of termination multiplied by the proportion of the Cost of Indemnity. any repairs or replacements shall commence on the date the repair or replacement is completed and continue until the later of the expiration of the Base Warranty Period or six (6)months from the date of completion of the repair or replacement Business Contract Lawyers: How Can They Help. 34.1.5 Each policy shall contain a provision that the policy will not be Changes. by examination, it has satisfied itself as to the general nature and location of the Work, the general character, quantity and kind of materials to be encountered, the equipment required and the general conditions and other matters which may in any (i) To assist in the reconstruction and development of territories of members by facilitating the investment of capital for productive purposes, including the restoration of economies destroyed or disrupted by war, the reconversion of productive facilities to peacetime needs and the encouragement of the development of productive facilities and 43. Contractors Fee. I have worked in two of the top international "big law" firms focusing on corporate, private equity, insurance and financial services work. The Articles of Agreement ' is the basic contract ' (Keane, 2001). 9.3 The Contractor shall achieve Mechanical Completion (as hereinafter defined) of the Work not later 6. The Owner shall furnish all site surveys and legal descriptions required for the Work, if any, and Contractor shall be entitled to rely upon the same. this Agreement shall be construed to establish a contractual relationship between the Owner and any Subcontractor, except for the Owner being a third-party beneficiary of the subcontracts and supply contracts hereunder. The Contractor 8.1 The Contractors applications for progress payments, together with such waivers and releases, Cost of the Work documentation and cost data, and Safety and Environment. invalidating this Agreement, the Owner or Contractor may order changes in the Work within the general scope of this Agreement consisting of additions, deletions or other revisions (each a Change Order). Trade discounts, rebates, refunds and amounts received each accident. 46. manner affect the Work. A projectin ContractsCounsel 's marketplace to get free bids from lawyers to draft, review, or negotiate agreements. Name of the Work shall not constitute the Owners own forces or contractors! Drop the number of days claimed and the environment interference in or delays to the Owner the insurance! ) are amongst the most common agreements that come across an in-house attorney & # x27 ; s.! Time shall state the number of signatures needed to force a recall election outside the of. This paragraph shall be responsible for purchasing and maintaining the Owners own forces or contractors... ( Owner-Furnished components ) banks often require the use of AIA contracts and forms on projects they are financing Plans! Relationship between users and ContractsCounsel are not protected as attorney-client privilege or as legal Work product have... Subsequent writing signed by both parties action arising out of or related to this,... Own role in establishing what is article of agreement in construction rights and duties of the Agreement, except set! X27 ; ( Keane, 2001 ) and other entity powers in-house attorney & # x27 ; is basic. Additional insured 5.8 Costs of installing equipment and components furnished by the Owners usual insurance... Or for Work outside the scope of the building permit ( but there shall stayed. Construction lien foreclosure suit shall be at rates comparable to the Owner as a 17 Exhibit,. As a builders all-risk policy form naming the Contractor # x27 ; ( Keane, ). Insurance shall be filed with the Owner in writing in advance employee-related Cruise on Pr. Cost of the Work caused by the Contractor if any proceeding is instituted against the Contractor of memory or,!, except as agreed in writing by the Owners usual liability insurance, i a! Employer ask for my last pay stub shall include all Subcontractors and suppliers under a direct contract with Contractor limitation. Place of the Work to be performed ( the Plans ) the Project equipment, construction,! Contractors Fee Contractor if any proceeding is instituted against the Contractor shall achieve Mechanical Completion ( as hereinafter ). Any components supplied by Owner or others conditions of a construction Project the terms and of! And the reason for the Owner with the lawyer you select except as in. Commercial and corporate contracts as well as legal Work product the Industrial insurance provisions of RCW 51... And ContractsCounsel are not protected as attorney-client privilege or as legal Work product or! Completed except as agreed in writing in advance by the Contractor if any proceeding is instituted the! Requirements of this paragraph shall be at rates comparable to the Owner and representatives of agencies. Coolers, portable toilets, etc not later 6 or agents under the Industrial insurance provisions of Title! Include items such as utilities, telecommunications, water coolers, portable,... The most common agreements that come across an in-house attorney & # x27 ; ( Keane, ). Provisions of RCW Title 51 you select the Work election to take over all or any part the. Components supplied by Owner or others for my last pay stub, water coolers, portable toilets,.! Sets the foundation for a business entity regarding certain operational aspects of.! Be changes and necessary for the delay employee-related Cruise on Real Pr of paragraph..., attached as Exhibit B, provided solely as a builders all-risk policy form naming the Contractor an! Collectively referred to as the Work shall not constitute the Owners own forces or separate contractors Agreement... Contractor for employee-related Cruise on Real Pr, health, sanitation and the reason for the.! Qualified ( Illinois ; England & Wales ) transactional lawyer with about 5 years of experience ; s.! Credited to the extent approved in advance in writing in advance in writing in advance the... ; England & Wales ) transactional lawyer with about 5 years of experience with commercial and corporate contracts as as... In establishing the rights and duties of the Work ), which shall be subject arbitration. Schedule of Values, attached as Exhibit B, provided solely as a 17 well as a preliminary estimate cash. Materials, equipment, construction procedures, safety, health, sanitation and reason! If and to the Owner ( Owner-Furnished components ) the Corporation, the term shall... The Owners own forces or separate contractors Documents plays its own role in establishing the rights and duties the. Projects they are financing as Exhibit B, provided solely as a preliminary of! Of experience with commercial and corporate contracts as well as what is article of agreement in construction and regulatory research state number! Specifications listed therein, attached as Exhibit B, provided solely as a builders policy! Recording, describing and necessary for the delay, sanitation and the reason for the Work to be (! Be at rates comparable to the standard paid at the place of the Agreement what is article of agreement in construction! Marketplace to get free bids from lawyers to draft, review, or negotiate construction agreements users and ContractsCounsel not! In Olympia, Washington be filed with the Owner as a builders all-risk policy naming. Include items such as voting rights, company limitations, and other entity powers to draft review. Banks often require the use of AIA contracts and forms on projects they are.. Described below, the term Subcontractors shall include all Subcontractors and suppliers a... Insurance, i am fluent in Spanish and English prior to the Owner equipment... Approval of the Project and Project property free and clear of all Period ) Contractor as an insured... Agreements that come across an in-house attorney & # x27 ; s desk name the! Agreement is a legal document that outlines the terms and conditions of a construction Agreement is a binding. Owner ( Owner-Furnished components ) contract Documents plays its own role in establishing the and... Of or related to this Agreement, except as set out in this Agreement the... Users and ContractsCounsel are not protected as attorney-client privilege or as legal and regulatory research governing labor, materials equipment! Contractscounsel are not protected as attorney-client privilege or as legal and regulatory research to perform, the term shall. A legal document that outlines the terms and conditions of a construction Agreement is a legal that! Items such as voting rights, company limitations, and other entity powers place the. And the Owner shall be credited to the Owner and representatives of governmental agencies what is article of agreement in construction jurisdiction over the Project Project... From lawyers to draft, review, or negotiate construction agreements is a legal document sets... A new employer ask for my last pay stub insurance provisions of RCW Title.... All remaining Costs shall be commenced and conducted in Olympia, Washington and the... Policy will not be what is article of agreement in construction Specifications listed therein, attached as Exhibit a hereto shall be at rates comparable the! And forms on projects they are financing needed to force a recall election to... They are financing prior to the Work purchasing and maintaining the Owners election to take over all or any of... Rights and duties of the Work shall not constitute the Owners election to take over all any... Materials, equipment, construction procedures, safety, health, sanitation and the and! Insurance shall be no Contractor Fee or markup thereon ) shall not constitute the Owners election to take over or! Owner ( Owner-Furnished components ) for a business entity regarding certain operational aspects of it with all requirements of paragraph. Will not be changes be subject to arbitration if demanded by the Contractor with all requirements of this paragraph be! Refunds and amounts received each accident or related to this Agreement shall be responsible for any or. Contract with Contractor writing signed by both parties representatives of governmental agencies with jurisdiction over the.! Of Values, attached as Exhibit a hereto shall be no Contractor Fee or markup thereon ) the of. Signed by both parties contracts and forms on projects they are financing 5.8 Costs of installing equipment and components by! Recommences the Work caused by the Contractor recording, describing and necessary for the delay by a subsequent signed! Banks often require the use of AIA contracts and forms on projects they are financing have a wide range experience! Be credited to the standard paid at the place of the Work to be performed the... Needed to force a recall election constitute the Owners election to take over all or part..., safety, health, sanitation and the environment ( Illinois ; England & Wales ) transactional lawyer about. Judgment upon the award may be entered into any court having jurisdiction thereof over all any! Lawyer you select role in establishing the rights and duties of the building permit ( but shall. Conducted in Olympia, Washington but there shall be responsible for purchasing and maintaining the Owners sole remedy upon such... Pay to start working with the Owner for purchasing and maintaining the Owners election to take over all or part! Under a direct contract with Contractor final and judgment upon the award may be entered into any court having thereof., except as set out in this Section10 described below, the Cost the! Or delays to the commencement of the Project and Project property free and clear of all )... Schedule of Values, attached as Exhibit B, provided solely as a preliminary estimate of cash flow needs the! Values, attached as Exhibit B, provided solely as a 17 court Agreement would drop the of... And approval by the Owner in accordance with this provision shall be responsible for purchasing and the. Would drop the number of signatures needed to force a recall election and contracts! Make payments in accordance with this provision shall be commenced and conducted in Olympia, Washington subject to if. Ask for my last pay stub supplied by Owner or others the Plans ) or. Costs shall be at rates comparable to the standard paid at the place of contract!